The term ‘The London Curtain and Blind Company’ or ‘us’ or ‘we’ refers to the owner of the website whose registered office is 20 Winchfield House, Highcliffe drive, London, SW15 4PX, United Kingdom. Our company registration number is 09682869 England. The term ‘you’ refers to the user or viewer of our website.
Should you contact us your email address will be kept on record that you contacted us along with our responses. This is to ensure we can follow up any further requirements with you.
Contracts and orders are accepted by The London Curtain and Blind Company Limited only subject to these General conditions of sale as set out herin and the Buyer shall be bound to such conditions. No modification of these conditions or the particulars contained in our acceptance will be recognised by us unless expressly accepted by us in writing. Unless so agreed any qualification thereof or difference contained in the buyer’s own order forms shall be inapplicable.
Payment terms for goods supplied and or installed are as stated in our written quotation. Where proforma or deposit payment has been requested no received order shall be processed until such payment has been made. Should any written quotation or order confirmation state a delivery or installation date, this date will not become applicable until the proforma or deposit has been received. Payment of outstanding balances is due as stated on our written quotation, order or confirmation invoice. Failure to make payment at the due date shall entitle us to levy interest on charges on any outstanding monies and to treat the contract as repudiated by the Buyer without prejudice to our rights to damages for breach of contract. Neither disputes arising under the contract nor factors outside the control of the Buyer shall entitle the Buyer to delay payment in full or in part.
Title in goods shall remain vested in us until payment thereof shall have been made by the buyer in full. We reserve the right to physically remove any goods supplied and or installed when payment has not been made in full by the Buyer within the time period as stated in the payment terms of our written quotation and or invoice.
4. Force Majeure
Should we be prevented from delivery or installation on the agreed date by strikes, lock-outs, act of God, war, fire, tempest, flood, accident, damage to goods, or delay in obtaining or inability to obtain by reasonable scarcity of materials or for any other cause beyond our control we may suspend delivery or installation until a reasonable time after the end of the happening and during such time as is reasonably incidental to the resumption of normal production or sale or cancel or vary the contract without compensation.
Every effort will be made to maintain delivery dates as stated in any written quotation or order confirmation which are approximate only, but we accept no liability for delay however occasioned or for the consequences of any delay.
6. Cancellation and returns
The Buyer shall not be entitled to cancel any contract or return goods for refund without prior consent of the Company (Which will be at the absolute discretion of the Company).
Should we attend a place to install goods on a date that has been prearranged with the Buyer and are unable to complete the installation due to site not being in a suitable condition, access not being available or Buyer refusing completion we reserve the right to charge for this aborted visit in addition to any other charges that have been previously paid or quoted.
Where cancellation, or rearrangement of a prearranged installation date by the Buyer less than 24 hours before the prearranged date will
We reserve the right to improve or amend the specification of any product at any time.
In addition to any right of Lien to which we may by law be entitled we shall have a general lien on all goods of the Buyer in our possession (although such goods or some of them may have been paid for) for unpaid price of any other goods sold and delivered to the buyer by us under the same or other contracts.
Our rights shall not be affected or restricted by any indulgence or forbearance granted to the Buyer. No Waiver by us or any breach shall operate as a waiver of any later breach.
The rights and obligations of the parties and all the terms and conditions hereof and any disputes arising out thereof shall be construed in accordance with English Law to the exclusive jurisdiction of the courts of which the buyer shall submit.